{"id":111807,"date":"2011-05-06T00:00:00","date_gmt":"2011-05-05T18:30:00","guid":{"rendered":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011"},"modified":"2017-09-21T23:46:01","modified_gmt":"2017-09-21T18:16:01","slug":"singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011","status":"publish","type":"post","link":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011","title":{"rendered":"Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011"},"content":{"rendered":"<div class=\"docsource_main\">Jharkhand High Court<\/div>\n<div class=\"doc_title\">Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011<\/div>\n<pre>           IN THE HIGH COURT OF JHARKHAND AT RANCHI\n                              A.A. No. 19 of 2009\n             (Singh Builders Syndicate Vrs. Central coalfields Ltd. &amp; Ors.)\n                                    With\n                            A.A No. 21 of 2009\n             (Singh Builders Syndicate Vrs. Central coalfields Ltd. &amp; Ors.)\n                                    With\n                         A.A. No. 22 of 2009\n             (Singh Builders Syndicate Vrs. Central coalfields Ltd. &amp; Ors.)\n                                   With\n                        A.A. No. 24 of 2009\n             (Vikram Transport Constn. Co. Vrs. Central coalfields Ltd. &amp; Ors.)\n\n                                    ------\n           CORAM:          HON'BLE MR. JUSTICE PRAKASH TATIA\n                                                     ------\n           For the Petitioners:     M\/s. Ajay Poddar (In all matters)\n           For the Respondents:     M\/s Ananda Sen   (In all matters)\n                                    Mr. Ranjan Kumar\n\n                                         ------                Dated 6th May, 2011\nPrakash Tatia, J.          Heard learned counsel for the parties.\n                    2.     All these matters are co-related having identical facts though\n                    the claims are different in each applications. So far as the different\n                    claims are concerned, it is apparent from the arbitration application.\n                    It is, therefore, by taking fact of one case, all these matters are\n                    being decided by a common order.\n                    3.     Learned counsel for the petitioner submitted that petitioner\n                    was allotted work for construction of 64 numbers of Miners quarters\n                    by the respondent-company in the year 1986 to be completed\n                    within 12 months from the date of work order. However, the said\n                    work was completed in the year 1989 i.e. after a delay of 24 months\n                    which delay was due to latches on the part of respondent as per\n                    the petitioner and the petitioner's dues were not paid. According to\n                    the learned counsel for the petitioner, the respondent-Company\n                    itself has given a letter dated 03.1.2005 to the petitioner showing\n                    therein the statement of all old cases of civil capital work done by\n                    the petitioner showing also Rs. 1,23,000\/- as dues amount against\n                    work and Rs.1,00,000\/- as earnest money.               Thereafter, the\n                    petitioner served notice upon the respondent-Company on\n                    12.4.2007<\/pre>\n<p> and also gave several reminders. Thereafter, the<br \/>\n                    petitioner had no option but to make a request for appointment of<br \/>\n                    an arbitrator in terms of the arbitration Clause, therefore he gave<br \/>\n                    notice for appointment of arbitrator to respondent.\n<\/p>\n<p>                    4.     It is clear from the facts stated in the petition itself that work<br \/>\n                    order was given in the year 1986 containing clause of completion of<br \/>\n                  work within 12 months and admittedly the work was completed in<br \/>\n                 the year 1989. Therefore, all amount of the petitioner became due<br \/>\n                 in the year 1989 itself but because of the letter dated 3.1.2005<br \/>\n                 addressed to the Staff Officer, Civil, one of the Branches of the<br \/>\n                 respondent Company endorsing the copy of the statement of the<br \/>\n                 old cases showing therein due amounts of petitioner also cannot<br \/>\n                 extend the period of limitation as the period of limitation by<br \/>\n                 acknowledgment or by part payment                can extend the period of<br \/>\n                 limitation of the debt which is within the period of the limitation.\n<\/p>\n<p>                 5.     Be that as it may, the Annexure-4 letter dated 3.10.2110<br \/>\n                 also neither shows payment nor the acknowledgment of the debt<br \/>\n                 but it is a statement sent by the respondent-Company to its own<br \/>\n                 office by endorsing the copy to petitioner. Even if the date of said<br \/>\n                 letter is taken into account i.e. 3.1.2005, for period of limitation,<br \/>\n                 then also these applications are barred by time as they have been<br \/>\n                 field in the year 2009. Since, the facts have come from the side of<br \/>\n                 the petitioner and are not disputed by the respondents, therefore,<br \/>\n                 the petitioners&#8217; claim appears to be stale and therefore, the<br \/>\n                 applications filed by the petitioner deserves to be dismissed.\n<\/p>\n<p>                 6.     These applications are accordingly dismissed.\n<\/p>\n<p>\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0\u00a0(Prakash\u00a0Tatia,\u00a0J.)<\/p>\n<p>Alankar\/Sudhir\n <\/p>\n","protected":false},"excerpt":{"rendered":"<p>Jharkhand High Court Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011 IN THE HIGH COURT OF JHARKHAND AT RANCHI A.A. No. 19 of 2009 (Singh Builders Syndicate Vrs. Central coalfields Ltd. &amp; Ors.) With A.A No. 21 of 2009 (Singh Builders Syndicate Vrs. Central coalfields Ltd. &amp; Ors.) With A.A. [&hellip;]<\/p>\n","protected":false},"author":1,"featured_media":0,"comment_status":"open","ping_status":"open","sticky":false,"template":"","format":"standard","meta":{"_lmt_disableupdate":"","_lmt_disable":"","_jetpack_memberships_contains_paid_content":false,"footnotes":""},"categories":[8,18],"tags":[],"class_list":["post-111807","post","type-post","status-publish","format-standard","hentry","category-high-court","category-jharkhand-high-court"],"yoast_head":"<!-- This site is optimized with the Yoast SEO plugin v27.0 - https:\/\/yoast.com\/product\/yoast-seo-wordpress\/ -->\n<title>Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011 - Free Judgements of Supreme Court &amp; High Court | Legal India<\/title>\n<meta name=\"robots\" content=\"index, follow, max-snippet:-1, max-image-preview:large, max-video-preview:-1\" \/>\n<link rel=\"canonical\" href=\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011\" \/>\n<meta property=\"og:locale\" content=\"en_US\" \/>\n<meta property=\"og:type\" content=\"article\" \/>\n<meta property=\"og:title\" content=\"Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011 - Free Judgements of Supreme Court &amp; High Court | Legal India\" \/>\n<meta property=\"og:url\" content=\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011\" \/>\n<meta property=\"og:site_name\" content=\"Free Judgements of Supreme Court &amp; High Court | Legal India\" \/>\n<meta property=\"article:publisher\" content=\"https:\/\/www.facebook.com\/LegalindiaCom\/\" \/>\n<meta property=\"article:published_time\" content=\"2011-05-05T18:30:00+00:00\" \/>\n<meta property=\"article:modified_time\" content=\"2017-09-21T18:16:01+00:00\" \/>\n<meta property=\"og:image\" content=\"https:\/\/i0.wp.com\/www.legalindia.com\/judgments\/wp-content\/uploads\/sites\/5\/2025\/09\/legal-india-icon.jpg?fit=512%2C512&ssl=1\" \/>\n\t<meta property=\"og:image:width\" content=\"512\" \/>\n\t<meta property=\"og:image:height\" content=\"512\" \/>\n\t<meta property=\"og:image:type\" content=\"image\/jpeg\" \/>\n<meta name=\"author\" content=\"Legal India Admin\" \/>\n<meta name=\"twitter:card\" content=\"summary_large_image\" \/>\n<meta name=\"twitter:creator\" content=\"@legaliadmin\" \/>\n<meta name=\"twitter:site\" content=\"@Legal_india\" \/>\n<meta name=\"twitter:label1\" content=\"Written by\" \/>\n\t<meta name=\"twitter:data1\" content=\"Legal India Admin\" \/>\n\t<meta name=\"twitter:label2\" content=\"Est. reading time\" \/>\n\t<meta name=\"twitter:data2\" content=\"3 minutes\" \/>\n<script type=\"application\/ld+json\" class=\"yoast-schema-graph\">{\"@context\":\"https:\/\/schema.org\",\"@graph\":[{\"@type\":\"Article\",\"@id\":\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011#article\",\"isPartOf\":{\"@id\":\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011\"},\"author\":{\"name\":\"Legal India Admin\",\"@id\":\"https:\/\/www.legalindia.com\/judgments\/#\/schema\/person\/0bfdffe9059fb8bb24a86d094609c5ea\"},\"headline\":\"Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011\",\"datePublished\":\"2011-05-05T18:30:00+00:00\",\"dateModified\":\"2017-09-21T18:16:01+00:00\",\"mainEntityOfPage\":{\"@id\":\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011\"},\"wordCount\":300,\"commentCount\":0,\"publisher\":{\"@id\":\"https:\/\/www.legalindia.com\/judgments\/#organization\"},\"articleSection\":[\"High Court\",\"Jharkhand High Court\"],\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"CommentAction\",\"name\":\"Comment\",\"target\":[\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011#respond\"]}]},{\"@type\":\"WebPage\",\"@id\":\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011\",\"url\":\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011\",\"name\":\"Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011 - Free Judgements of Supreme Court &amp; High Court | Legal India\",\"isPartOf\":{\"@id\":\"https:\/\/www.legalindia.com\/judgments\/#website\"},\"datePublished\":\"2011-05-05T18:30:00+00:00\",\"dateModified\":\"2017-09-21T18:16:01+00:00\",\"breadcrumb\":{\"@id\":\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011#breadcrumb\"},\"inLanguage\":\"en-US\",\"potentialAction\":[{\"@type\":\"ReadAction\",\"target\":[\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011\"]}]},{\"@type\":\"BreadcrumbList\",\"@id\":\"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011#breadcrumb\",\"itemListElement\":[{\"@type\":\"ListItem\",\"position\":1,\"name\":\"Home\",\"item\":\"https:\/\/www.legalindia.com\/judgments\/\"},{\"@type\":\"ListItem\",\"position\":2,\"name\":\"Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011\"}]},{\"@type\":\"WebSite\",\"@id\":\"https:\/\/www.legalindia.com\/judgments\/#website\",\"url\":\"https:\/\/www.legalindia.com\/judgments\/\",\"name\":\"Free Judgements of Supreme Court & High Court | Legal India\",\"description\":\"Search and read the latest judgements, orders, and rulings from the Supreme Court of India and all High Courts. A comprehensive database for lawyers, advocates, and law students.\",\"publisher\":{\"@id\":\"https:\/\/www.legalindia.com\/judgments\/#organization\"},\"alternateName\":\"Free judgements of Supreme Court & High Court of India | Legal India\",\"potentialAction\":[{\"@type\":\"SearchAction\",\"target\":{\"@type\":\"EntryPoint\",\"urlTemplate\":\"https:\/\/www.legalindia.com\/judgments\/?s={search_term_string}\"},\"query-input\":{\"@type\":\"PropertyValueSpecification\",\"valueRequired\":true,\"valueName\":\"search_term_string\"}}],\"inLanguage\":\"en-US\"},{\"@type\":\"Organization\",\"@id\":\"https:\/\/www.legalindia.com\/judgments\/#organization\",\"name\":\"Judgements of Supreme Court & High Court | Legal India\",\"alternateName\":\"Legal India\",\"url\":\"https:\/\/www.legalindia.com\/judgments\/\",\"logo\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.legalindia.com\/judgments\/#\/schema\/logo\/image\/\",\"url\":\"https:\/\/www.legalindia.com\/judgments\/wp-content\/uploads\/sites\/5\/2025\/09\/legal-india-icon.jpg\",\"contentUrl\":\"https:\/\/www.legalindia.com\/judgments\/wp-content\/uploads\/sites\/5\/2025\/09\/legal-india-icon.jpg\",\"width\":512,\"height\":512,\"caption\":\"Judgements of Supreme Court & High Court | Legal India\"},\"image\":{\"@id\":\"https:\/\/www.legalindia.com\/judgments\/#\/schema\/logo\/image\/\"},\"sameAs\":[\"https:\/\/www.facebook.com\/LegalindiaCom\/\",\"https:\/\/x.com\/Legal_india\"]},{\"@type\":\"Person\",\"@id\":\"https:\/\/www.legalindia.com\/judgments\/#\/schema\/person\/0bfdffe9059fb8bb24a86d094609c5ea\",\"name\":\"Legal India Admin\",\"image\":{\"@type\":\"ImageObject\",\"inLanguage\":\"en-US\",\"@id\":\"https:\/\/www.legalindia.com\/judgments\/#\/schema\/person\/image\/\",\"url\":\"https:\/\/secure.gravatar.com\/avatar\/4faa9d728ed1af3b73d52225c7f12901ac726fe6f7ea0a3348a1d51f3a930987?s=96&d=mm&r=g\",\"contentUrl\":\"https:\/\/secure.gravatar.com\/avatar\/4faa9d728ed1af3b73d52225c7f12901ac726fe6f7ea0a3348a1d51f3a930987?s=96&d=mm&r=g\",\"caption\":\"Legal India Admin\"},\"sameAs\":[\"https:\/\/www.legalindia.com\",\"https:\/\/x.com\/legaliadmin\"],\"url\":\"https:\/\/www.legalindia.com\/judgments\/author\/legal-india-admin\"}]}<\/script>\n<!-- \/ Yoast SEO plugin. -->","yoast_head_json":{"title":"Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011 - Free Judgements of Supreme Court &amp; High Court | Legal India","robots":{"index":"index","follow":"follow","max-snippet":"max-snippet:-1","max-image-preview":"max-image-preview:large","max-video-preview":"max-video-preview:-1"},"canonical":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011","og_locale":"en_US","og_type":"article","og_title":"Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011 - Free Judgements of Supreme Court &amp; High Court | Legal India","og_url":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011","og_site_name":"Free Judgements of Supreme Court &amp; High Court | Legal India","article_publisher":"https:\/\/www.facebook.com\/LegalindiaCom\/","article_published_time":"2011-05-05T18:30:00+00:00","article_modified_time":"2017-09-21T18:16:01+00:00","og_image":[{"width":512,"height":512,"url":"https:\/\/i0.wp.com\/www.legalindia.com\/judgments\/wp-content\/uploads\/sites\/5\/2025\/09\/legal-india-icon.jpg?fit=512%2C512&ssl=1","type":"image\/jpeg"}],"author":"Legal India Admin","twitter_card":"summary_large_image","twitter_creator":"@legaliadmin","twitter_site":"@Legal_india","twitter_misc":{"Written by":"Legal India Admin","Est. reading time":"3 minutes"},"schema":{"@context":"https:\/\/schema.org","@graph":[{"@type":"Article","@id":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011#article","isPartOf":{"@id":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011"},"author":{"name":"Legal India Admin","@id":"https:\/\/www.legalindia.com\/judgments\/#\/schema\/person\/0bfdffe9059fb8bb24a86d094609c5ea"},"headline":"Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011","datePublished":"2011-05-05T18:30:00+00:00","dateModified":"2017-09-21T18:16:01+00:00","mainEntityOfPage":{"@id":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011"},"wordCount":300,"commentCount":0,"publisher":{"@id":"https:\/\/www.legalindia.com\/judgments\/#organization"},"articleSection":["High Court","Jharkhand High Court"],"inLanguage":"en-US","potentialAction":[{"@type":"CommentAction","name":"Comment","target":["https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011#respond"]}]},{"@type":"WebPage","@id":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011","url":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011","name":"Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011 - Free Judgements of Supreme Court &amp; High Court | Legal India","isPartOf":{"@id":"https:\/\/www.legalindia.com\/judgments\/#website"},"datePublished":"2011-05-05T18:30:00+00:00","dateModified":"2017-09-21T18:16:01+00:00","breadcrumb":{"@id":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011#breadcrumb"},"inLanguage":"en-US","potentialAction":[{"@type":"ReadAction","target":["https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011"]}]},{"@type":"BreadcrumbList","@id":"https:\/\/www.legalindia.com\/judgments\/singh-builders-syndicate-vs-central-coalfields-ltd-ors-on-6-may-2011#breadcrumb","itemListElement":[{"@type":"ListItem","position":1,"name":"Home","item":"https:\/\/www.legalindia.com\/judgments\/"},{"@type":"ListItem","position":2,"name":"Singh Builders Syndicate vs Central Coalfields Ltd. &amp; Ors on 6 May, 2011"}]},{"@type":"WebSite","@id":"https:\/\/www.legalindia.com\/judgments\/#website","url":"https:\/\/www.legalindia.com\/judgments\/","name":"Free Judgements of Supreme Court & High Court | Legal India","description":"Search and read the latest judgements, orders, and rulings from the Supreme Court of India and all High Courts. A comprehensive database for lawyers, advocates, and law students.","publisher":{"@id":"https:\/\/www.legalindia.com\/judgments\/#organization"},"alternateName":"Free judgements of Supreme Court & High Court of India | Legal India","potentialAction":[{"@type":"SearchAction","target":{"@type":"EntryPoint","urlTemplate":"https:\/\/www.legalindia.com\/judgments\/?s={search_term_string}"},"query-input":{"@type":"PropertyValueSpecification","valueRequired":true,"valueName":"search_term_string"}}],"inLanguage":"en-US"},{"@type":"Organization","@id":"https:\/\/www.legalindia.com\/judgments\/#organization","name":"Judgements of Supreme Court & High Court | Legal India","alternateName":"Legal India","url":"https:\/\/www.legalindia.com\/judgments\/","logo":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.legalindia.com\/judgments\/#\/schema\/logo\/image\/","url":"https:\/\/www.legalindia.com\/judgments\/wp-content\/uploads\/sites\/5\/2025\/09\/legal-india-icon.jpg","contentUrl":"https:\/\/www.legalindia.com\/judgments\/wp-content\/uploads\/sites\/5\/2025\/09\/legal-india-icon.jpg","width":512,"height":512,"caption":"Judgements of Supreme Court & High Court | Legal India"},"image":{"@id":"https:\/\/www.legalindia.com\/judgments\/#\/schema\/logo\/image\/"},"sameAs":["https:\/\/www.facebook.com\/LegalindiaCom\/","https:\/\/x.com\/Legal_india"]},{"@type":"Person","@id":"https:\/\/www.legalindia.com\/judgments\/#\/schema\/person\/0bfdffe9059fb8bb24a86d094609c5ea","name":"Legal India Admin","image":{"@type":"ImageObject","inLanguage":"en-US","@id":"https:\/\/www.legalindia.com\/judgments\/#\/schema\/person\/image\/","url":"https:\/\/secure.gravatar.com\/avatar\/4faa9d728ed1af3b73d52225c7f12901ac726fe6f7ea0a3348a1d51f3a930987?s=96&d=mm&r=g","contentUrl":"https:\/\/secure.gravatar.com\/avatar\/4faa9d728ed1af3b73d52225c7f12901ac726fe6f7ea0a3348a1d51f3a930987?s=96&d=mm&r=g","caption":"Legal India Admin"},"sameAs":["https:\/\/www.legalindia.com","https:\/\/x.com\/legaliadmin"],"url":"https:\/\/www.legalindia.com\/judgments\/author\/legal-india-admin"}]}},"modified_by":null,"jetpack_featured_media_url":"","jetpack_sharing_enabled":true,"jetpack_likes_enabled":true,"jetpack-related-posts":[],"_links":{"self":[{"href":"https:\/\/www.legalindia.com\/judgments\/wp-json\/wp\/v2\/posts\/111807","targetHints":{"allow":["GET"]}}],"collection":[{"href":"https:\/\/www.legalindia.com\/judgments\/wp-json\/wp\/v2\/posts"}],"about":[{"href":"https:\/\/www.legalindia.com\/judgments\/wp-json\/wp\/v2\/types\/post"}],"author":[{"embeddable":true,"href":"https:\/\/www.legalindia.com\/judgments\/wp-json\/wp\/v2\/users\/1"}],"replies":[{"embeddable":true,"href":"https:\/\/www.legalindia.com\/judgments\/wp-json\/wp\/v2\/comments?post=111807"}],"version-history":[{"count":0,"href":"https:\/\/www.legalindia.com\/judgments\/wp-json\/wp\/v2\/posts\/111807\/revisions"}],"wp:attachment":[{"href":"https:\/\/www.legalindia.com\/judgments\/wp-json\/wp\/v2\/media?parent=111807"}],"wp:term":[{"taxonomy":"category","embeddable":true,"href":"https:\/\/www.legalindia.com\/judgments\/wp-json\/wp\/v2\/categories?post=111807"},{"taxonomy":"post_tag","embeddable":true,"href":"https:\/\/www.legalindia.com\/judgments\/wp-json\/wp\/v2\/tags?post=111807"}],"curies":[{"name":"wp","href":"https:\/\/api.w.org\/{rel}","templated":true}]}}